Last Updated: 09 October 2026

Welcome to CYV Solutions.

By purchasing or using any service provided by CYV Solutions ("Company", "We", "Us", or "Our"), you agree to be bound by the Terms of Service outlined below.

Services

CYV Solutions provides services including but not limited to:

Website Development
E-Commerce Development
CRM Development
AI Automation
SaaS Solutions
Digital Marketing
SEO Services
Mobile Application Development
Branding & Design Services

Project Acceptance

Any payment, advance, token amount, or invoice settlement shall constitute acceptance of these Terms.

Payment Terms

All projects require advance payment before work begins.
Milestone-based projects must follow the agreed payment schedule.
Final delivery will only occur after complete payment clearance.

Project Delivery

Estimated timelines are provided for planning purposes only.

Delivery dates may vary based on:

Client delays
Revision requests
Third-party services
Technical requirements

Revisions

Two rounds of revisions are included unless otherwise agreed.
Additional revisions may incur extra charges.

Ownership

Project ownership transfers only after full payment is received.

Until then, all intellectual property remains the property of CYV Solutions.

Service Suspension

Services may be suspended for:

Non-payment
Abuse
Fraud
Violation of these terms

Limitation of Liability

CYV Solutions shall not be liable for indirect, incidental, or consequential damages arising from use of our services.

Governing Law

These Terms are governed by the laws of India.

Jurisdiction shall remain with the courts of West Godavari District, Andhra Pradesh.